Bill Sponsor
BILLSPONSOR
Bill Sponsor
Politicians
Bills
Senate Bill 565
116th Congress(2019-2020)
Billion Dollar Boondoggle Act of 2019
Introduced
Introduced
Introduced in Senate on Feb 26, 2019
Overview
Text
About Linkage
Multiple bills can contain the same text. This could be an identical bill in the opposite chamber or a smaller bill with a section embedded in a larger bill.
Bill Sponsor regularly scans bill texts to find sections that are contained in other bill texts. When a matching section is found, the bills containing that section can be viewed by clicking "View Bills" within the bill text section.
Bill Sponsor is currently only finding exact word-for-word section matches. In a future release, partial matches will be included.
About Linkage
Multiple bills can contain the same text. This could be an identical bill in the opposite chamber or a smaller bill with a section embedded in a larger bill.
Bill Sponsor regularly scans bill texts to find sections that are contained in other bill texts. When a matching section is found, the bills containing that section can be viewed by clicking "View Bills" within the bill text section.
Bill Sponsor is currently only finding exact word-for-word section matches. In a future release, partial matches will be included.
Jump To
S. 565 (Reported-in-Senate)

Calendar No. 435

116th CONGRESS
2d Session
S. 565

[Report No. 116–220]


To require the Director of the Office of Management and Budget to submit to Congress an annual report on projects that are over budget and behind schedule, and for other purposes.

IN THE SENATE OF THE UNITED STATES

February 26, 2019

Ms. Ernst (for herself, Mr. Braun, Mr. Paul, Mr. Lankford, Mr. Peters, and Mr. Scott of Florida) introduced the following bill; which was read twice and referred to the Committee on Homeland Security and Governmental Affairs

March 2, 2020

Reported by Mr. Johnson, with an amendment

[Strike out all after the enacting clause and insert the part printed in italic]

A BILL

To require the Director of the Office of Management and Budget to submit to Congress an annual report on projects that are over budget and behind schedule, and for other purposes.

Be it enacted by the Senate and House of Representatives of the United States of America in Congress assembled,

SECTION 1. Short title.

This Act may be cited as the “Billion Dollar Boondoggle Act of 2019”.

SEC. 2. Annual report.

(a) Definition of covered agency.—In this section, the term “covered agency” means—

(1) an Executive agency, as defined in section 105 of title 5, United States Code; and

(2) an independent regulatory agency, as defined in section 3502 of title 44, United States Code.

(b) Requirement.—Not later than 1 year after the date of enactment of this Act, and every year thereafter, the Director of the Office of Management and Budget shall submit to Congress and post on the website of the Office of Management and Budget a report on each project funded by a covered agency—

(1) that is more than 5 years behind schedule; or

(2) for which the amount spent on the project is not less than $1,000,000,000 more than the original cost estimate for the project.

(c) Contents.—Each report submitted and posted under subsection (b) shall include, for each project included in the report—

(1) a brief description of the project, including—

(A) the purpose of the project;

(B) each location in which the project is carried out;

(C) the year in which the project was initiated;

(D) the Federal share of the total cost of the project; and

(E) each primary contractor, subcontractor, grant recipient, and subgrantee recipient of the project;

(2) an explanation of any change to the original scope of the project, including by the addition or narrowing of the initial requirements of the project;

(3) the original expected date for completion of the project;

(4) the current expected date for completion of the project;

(5) the original cost estimate for the project, as adjusted to reflect increases in the Consumer Price Index for All Urban Consumers, as published by the Bureau of Labor Statistics;

(6) the current cost estimate for the project, as adjusted to reflect increases in the Consumer Price Index for All Urban Consumers, as published by the Bureau of Labor Statistics;

(7) an explanation for a delay in completion or increase in the original cost estimate for the project; and

(8) the amount of and rationale for any award, incentive fee, or other type of bonus, if any, awarded for the project.

(d) Submission with budget.—Section 1105(a) of title 31, United States Code, is amended by adding at the end the following:

“(40) the report required under section 2(b) of the Billion Dollar Boondoggle Act of 2019 for the calendar year in which the fiscal year covered by the budget begins.”.

SECTION 1. Short title.

This Act may be cited as the “Billion Dollar Boondoggle Act of 2019”.

SEC. 2. Annual report.

(a) Definitions.—In this section—

(1) the term “covered agency” means—

(A) an Executive agency, as defined in section 105 of title 5, United States Code; and

(B) an independent regulatory agency, as defined in section 3502 of title 44, United States Code;

(2) the term “covered project” means a project funded by a covered agency—

(A) that is more than 5 years behind schedule; or

(B) for which the amount spent on the project is not less than $1,000,000,000 more than the original cost estimate for the project; and

(3) the term “project” means a major acquisition, a major defense acquisition program (as defined in section 2430 of title 10, United States Code), a procurement, a construction project, a remediation or clean-up effort, or any other time-limited endeavor, that is not funded through direct spending (as defined in section 250(c) of the Balanced Budget and Emergency Deficit Control Act of 1985 (2 U.S.C. 900(c)).

(b) Requirement.—Not later than 1 year after the date of enactment of this Act, the Director of the Office of Management and Budget shall issue guidance requiring covered agencies to include, on an annual basis in a report described in paragraph (2) of section 3516(a) of title 31, United States Code, or a consolidated report described in paragraph (1) of such section, information relating to each covered project of the covered agency, which shall include—

(1) a brief description of the covered project, including—

(A) the purpose of the covered project;

(B) each location in which the covered project is carried out;

(C) the contract or award number of the covered project, where applicable;

(D) the year in which the covered project was initiated;

(E) the Federal share of the total cost of the covered project; and

(F) each primary contractor, subcontractor, grant recipient, and subgrantee recipient of the covered project;

(2) an explanation of any change to the original scope of the covered project, including by the addition or narrowing of the initial requirements of the covered project;

(3) the original expected date for completion of the covered project;

(4) the current expected date for completion of the covered project;

(5) the original cost estimate for the covered project, as adjusted to reflect increases in the Consumer Price Index for All Urban Consumers, as published by the Bureau of Labor Statistics;

(6) the current cost estimate for the covered project, as adjusted to reflect increases in the Consumer Price Index for All Urban Consumers, as published by the Bureau of Labor Statistics;

(7) an explanation for a delay in completion or an increase in the original cost estimate for the covered project, including, where applicable, any impact of insufficient or delayed appropriations; and

(8) the amount of and rationale for any award, incentive fee, or other type of bonus, if any, awarded for the covered project.

Calendar No. 435

116th CONGRESS
     2d Session
S. 565
[Report No. 116–220]
A BILL
To require the Director of the Office of Management and Budget to submit to Congress an annual report on projects that are over budget and behind schedule, and for other purposes.
March 2, 2020
Reported with an amendment